FAR 52.211-10 - Commencement, Prosecution, and Completion of Work
Prescribed in 11.404(b) | ||
| Effective Date: | 1 April 1984 | |
| Clause or Provision: | Clause | |
| Provision or Clause Number: | 52.211-10 - Commencement, Prosecution, and Completion of Work | |
| Principle Type And/Or Purpose of Contract: | ||
| Required: | Fixed Price, Construction | |
| Applicable: | ||
| Optional: | Utility Services; Simplified Acquisition Procedures (Excludes Micro-Purchase); Facilities; Indefinite Delivery; Dismantling, Demolition or Removal of Improvements; Leasing of Motor Vehicles; Time & Material/Labor Hour; Cost Reimbursement, Construction; Fixed Price, Service; Cost Reimbursement, Supply; Cost Reimbursement, Service | |
| Subject: | Delivery or Performance Schedules | |
| ProcurementType: | ||
| Contract Threshold: | ||
| Prescription Overview: |
Prescription(b) Construction. The contracting officer shall insert the clause at 52.211-10, Commencement, Prosecution, and Completion of Work, in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts. If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a certain day, the contracting officer may use the clause with its Alternate I. | |
| Clause Overview: |
ClauseThe Contractor shall be required to (a) commence work under this contract within _________ [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than ______________.* The time stated for completion shall include final cleanup of the premises.
AlternateAlternate I (Apr 1984). If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a certain day, add the following paragraph to the basic clause: The completion date is based on the assumption that the successful offeror will receive the notice to proceed by _______________ [Contracting Officer insert date]. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer. | |
| Important Notes/Requirements: | ||
| Subcontract Threshold: | ||
| Incorporated by Reference: | Yes | |
| Uniform Contract Format: | ||
| Editor: | Marshall | |
Personal notes.
