DFARS 252.219-7011 Notification to Delay Performance

***

Prescribed in 219.811-3(3)
Effective Date:	1 June 1998
Clause or Provision:	Clause
Provision or Clause Number:	S 252.219-7011 Notification to Delay Performance
Principle Type And/Or Purpose of Contract:
Required:
Applicable:
Optional:
Subject:
ProcurementType:
Contract Threshold:
Prescription Overview:	Prescription (3) Use the clause at 252.219-7011, Notification to Delay Performance, in solicitations and purchase orders issued under the PA cited in 219.800.
Clause Overview:	Clause NOTIFICATION TO DELAY PERFORMANCE (JUN 1998) The Contractor shall not begin performance under this purchase order until 2 working days have passed from the date of its receipt. Unless the Contractor receives notification from the Small Business Administration that it is ineligible for this 8(a) award, or otherwise receives instructions from the Contracting Officer, performance under this purchase order may begin on the third working day following receipt of the purchase order. If a determination of ineligibility is issued within the 2-day period, the purchase order shall be considered canceled.
Important Notes/Requirements:
Subcontract Threshold:
Incorporated by Reference:	Yes
Uniform Contract Format:
Editor:	Marshall

---

Personal notes.